In 1989, the Texas Legislature passed the Residential Construction Liability Act, which preempts or modifies many types of claims for damages arising from any “construction defect.” In this case, the court of appeals applied the RCLA to bar a homeowner’s claim for lost rental value of his condominium during the long delay occasioned by the remodeling contractor before the contract was finally terminated. Under the statute, a “construction defect” is defined broadly to include any matter “concerning the design, construction, or repair of a new residence, of an alteration of or repair or addition to an existing residence, or of an appurtenance to a residence, on which a person has a complaint against a contractor.” Tex. Prop. Code § 27.001(4). Because the contractor’s delay was one such matter, the court held that the RCLA governed the claim for damages caused by the delay. The plaintiff’s claim could not succeed under the RCLA for two reasons. First, the homeowner had failed to give the contractor notice of the claim, as required by the statute. Second, the plaintiff was seeking to recover the rental value of his own home during the time that completion of the remodeling was delayed, while the RCLA would only allow the homeowner to recover the cost of substitute housing. Id. § 27.004(g)(4). The court of appeals therefore rendered judgment that the plaintiff take nothinig and remanded the case to the trial court to determine the amount of attorney fees the defendant was entitled to under an agreement of the parties.
Timmerman v. Dale, No. 05-11-01690-CV